Subcontractor Agreement Generator
Create comprehensive subcontractor agreements for construction projects
1
2
3
Step 1: General Contractor & Subcontractor Information
General Contractor Information
General Contractor Name
*
Business Entity Type
*
Select Entity Type
Corporation
LLC
Partnership
Sole Proprietorship
Business Address
*
Phone Number
*
Email Address
*
Contractor License Number
Primary Project Name
Subcontractor Information
Subcontractor Business Name
*
Business Entity Type
*
Select Entity Type
Corporation
LLC
Partnership
Sole Proprietorship
Business Address
*
Phone Number
*
Email Address
*
Trade License Number
License State
Select State
California
Texas
Florida
New York
Illinois
Trade Specialty
*
Select Trade Specialty
Electrical
Plumbing
HVAC
Roofing
Framing/Carpentry
Drywall
Painting
Flooring
Concrete
Excavation
Insulation
Landscaping
Other Specialty
Professional Certifications
Step 2: Scope of Work & Project Details
Project Information
Project Site Address
*
Project Type
Select Project Type
New Construction
Renovation
Addition
Repair Work
Commercial Project
Residential Project
Total Project Value ($)
General Project Description
Subcontractor Scope of Work
Detailed Work Description
*
Specific Work Locations
Materials & Supplies
Select Material Responsibility
Subcontractor Provides All Materials
General Contractor Provides Materials
Shared Responsibility
Owner Provides Materials
Material Specifications
Equipment & Tools
Select Equipment Responsibility
Subcontractor Provides All Tools/Equipment
General Contractor Provides Equipment
Shared Responsibility
Quality Standards & Specifications
Work Specifically Excluded
Schedule & Coordination
Work Start Date
*
Work Completion Date
*
Work Schedule & Hours
Coordination Requirements
Key Milestones
Step 3: Payment Terms & Legal Conditions
Contract Price & Payment
Total Contract Amount ($)
*
Payment Basis
*
Select Payment Basis
Lump Sum
Time & Materials
Unit Price
Cost Plus Fee
Payment Schedule
Select Payment Schedule
Progress Payments
Milestone Payments
Payment Upon Completion
Monthly Billing
Payment Terms Details
Retainage Percentage (%)
Retainage Release
Select Release Terms
At Substantial Completion
At Final Completion
30 Days After Completion
After Warranty Period
Change Order Procedure
Insurance & Safety Requirements
Required Insurance Coverage
General Liability Insurance
Workers' Compensation
Automobile Liability
Professional Liability
Minimum Insurance Amount ($)
Additional Insured
Select Option
General Contractor Only
Contractor & Owner
As Required by Contract
Safety Requirements
Warranty Period
Select Warranty Period
One Year
Two Years
90 Days
As Per Main Contract
No Warranty
Legal Terms & Conditions
Independent Contractor Status
Subcontractor is an independent contractor, not an employee
Dispute Resolution
Select Resolution Method
Binding Arbitration
Mediation
Court Litigation
Negotiation then Arbitration
Termination Rights
Select Termination Rights
For Cause Only
For Convenience
Breach of Contract Only
Mutual Agreement
Governing Law (State)
*
Select State
California
Texas
Florida
New York
Illinois
Lien Waiver Requirements
Compliance Requirements
Additional Terms & Conditions
Previous
Next
Generate Subcontractor Agreement